Appellant / Complainant
Purnima Kumar
Respondent
Omaxe Limited
omaxe limited
₹36,56,733
Appellant
Legal Issues & Claims Raised
Case Procedural History & Progression Tree
Visual step-by-step tree detailing dispute origin, interim hearings, and final tribunal ruling.
Complaint Filing & Dispute Registration
Complaint registered under Case ID 0901126022922022 by Purnima Kumar against Omaxe Limited before up_rera.
Hearing
The Tribunal set aside the previous order, ruling that the promoter engaged in unfair and fraudulent practices by collecting funds before obtaining layout sanctions. The appellant is entitled to interest on their deposit from 2011 (minus a 48-month construction period) and the respondent is directed to face penal consequences under Chapter VIII of the RERA Act.
Hearing
Due to the respondent's failure to pay costs and a bounced cheque, the Tribunal ordered that the appeal shall proceed ex-parte against Omaxe Limited.
Hearing
The respondent has complied with the previous order by paying a cost of Rs. 20,000 to the appellant via cheque, and the matter is scheduled for hearing on 08.04.2025.
Hearing
The Tribunal adjourned the appeal to 17.03.2025 and imposed a cost of Rs 20,000/- on the respondent, payable to the appellant, due to the respondent's request for adjournment.
Hearing
The Tribunal has scheduled the appeal for orders or hearing on 18.02.2025.
Hearing
The Tribunal granted a request for adjournment made by the appellant's counsel and rescheduled the hearing for January 30, 2025.
Hearing
The Tribunal has granted a request by the appellant's counsel to reschedule the appeal for a final hearing on 10.01.2025.
Hearing
The Tribunal granted adjournment applications from both parties and rescheduled the hearing for the appeal to December 6, 2024.
Hearing
The Tribunal granted the appellant's request for a short adjournment to review additional documents filed by the respondent and rescheduled the hearing to 07.11.2024.
Hearing
The Tribunal granted the respondent 10 days to file documents and adjourned the appeal to 15.10.2024.
Hearing
The Tribunal granted the respondent one week to prepare their brief and scheduled the appeal for orders/hearing on 05.09.2024.
Hearing
Upon the joint request of the counsels for both parties, the Tribunal adjourned the appeal and scheduled it for a hearing on 06.08.2024.
Hearing
The Tribunal noted the presence of the respondent's counsel and the unavailability of the appellant's counsel, subsequently scheduling the appeal for a hearing on 04.07.2024.
Hearing
The Tribunal granted an adjournment requested by the appellant's counsel and scheduled the appeal for a hearing on 06.05.2024.
Hearing
The Tribunal has ordered the appeal to be listed for a hearing on 04.04.2024.
Hearing
The Tribunal noted the absence of both parties and adjourned the matter to 01.03.2024 for hearing.
Hearing
The Tribunal adjourned the proceedings due to a call for lawyers to abstain from judicial work by the Bar Council of Uttar Pradesh and rescheduled the hearing for 26.10.2023.
Hearing
The matter was adjourned due to lack of time, with the court directing the case to be listed again on 26.07.2023.
Hearing
The Tribunal has rescheduled the hearing of Appeal-240/2022 to 15.05.2023 following a joint request from the counsels of both parties.
Hearing
The Tribunal has adjourned the matter to 26.04.2023 for orders/hearing due to the absence of the appellant's counsel.
Exchange of pleadings
The Tribunal granted a request by the appellant's counsel to adjourn the matter and rescheduled the hearing for 16.03.2023.
Exchange of pleadings
This text represents the header/caption of an appeal (APPEAL-240/2022) before the U.P. Real Estate Appellate Tribunal, involving Purnima Kumar vs. Omaxe Limited, but contains no substantive ruling or directive.
Exchange of pleadings
The Tribunal granted an adjournment requested by the respondent's counsel and rescheduled the appeal for hearing on 14.10.2022.
Exchange of pleadings
The Tribunal adjourned the matter in the interest of justice and scheduled the case for further hearing on 12.09.2022.
Hearing on Appeal
The Tribunal directed the appellant's counsel to file a replication in response to the reply already submitted by the respondent regarding the memo of appeal.
Hearing on Appeal
The Tribunal issued a notice to the respondent and provided specific procedural instructions for the service of the appeal memo and the filing of objections and replies.
Tribunal Order #0901126022922022-10-04-2025
The Tribunal set aside the previous order, ruling that the promoter engaged in unfair and fraudulent practices by collecting funds before obtaining layout sanctions. The appellant is entitled to interest on their deposit from 2011 (minus a 48-month construction period) and the respondent is directed to face penal consequences under Chapter VIII of the RERA Act.
Tribunal Order #0901126022922022-18-02-2025
The Tribunal adjourned the appeal to 17.03.2025 and imposed a cost of Rs 20,000/- on the respondent, payable to the appellant, due to the respondent's request for adjournment.
Tribunal Order #0901126022922022-08-04-2025
Due to the respondent's failure to pay costs and a bounced cheque, the Tribunal ordered that the appeal shall proceed ex-parte against Omaxe Limited.
Tribunal Order #0901126022922022-17-03-2025
The respondent has complied with the previous order by paying a cost of Rs. 20,000 to the appellant via cheque, and the matter is scheduled for hearing on 08.04.2025.
Tribunal Disposal & Final Award Ruling
The Tribunal set aside the previous order, ruling that the promoter engaged in unfair and fraudulent practices by collecting funds before obtaining layout sanctions. The appellant is entitled to interest on their deposit from 2011 (minus a 48-month construction period) and the respondent is directed to face penal consequences under Chapter VIII of the RERA Act. Awarded in favor of Appellant. Awarded interest rate: MCLR+1 percent.
Final Tribunal Order & Ruling Verdict Summary
Official Ruling Summary
The Tribunal set aside the previous order, ruling that the promoter engaged in unfair and fraudulent practices by collecting funds before obtaining layout sanctions. The appellant is entitled to interest on their deposit from 2011 (minus a 48-month construction period) and the respondent is directed to face penal consequences under Chapter VIII of the RERA Act.
Ruling Awarded To
Appellant
Awarded Interest Rate
MCLR+1 percent
Interest Period
w.e.f. 22.03.2011 till the date obtaining OC/CC or handing over possession of the unit whichever is later; the period of 48 months would be deducted from the delayed period
Statutory Sections Cited (RERA Act 2016)
Appearing Legal Counsel & Advocates
Appellant Advocate(s)
- Vinay Lakhani
- Saurabh Misra
Respondent Advocate(s)
- Vineet K Singh Bisen
Official RERA Tribunal Orders (4)
The Tribunal set aside the previous order, ruling that the promoter engaged in unfair and fraudulent practices by collecting funds before obtaining layout sanctions. The appellant is entitled to interest on their deposit from 2011 (minus a 48-month construction period) and the respondent is directed to face penal consequences under Chapter VIII of the RERA Act.
The Tribunal adjourned the appeal to 17.03.2025 and imposed a cost of Rs 20,000/- on the respondent, payable to the appellant, due to the respondent's request for adjournment.
Due to the respondent's failure to pay costs and a bounced cheque, the Tribunal ordered that the appeal shall proceed ex-parte against Omaxe Limited.
The respondent has complied with the previous order by paying a cost of Rs. 20,000 to the appellant via cheque, and the matter is scheduled for hearing on 08.04.2025.
Need to research all rulings for omaxe limited?
Extract builder dossiers, check execution status, and draft RERA appeal petitions in minutes using TathyaGrid.